《公路工程标准勘察设计合同（中英文对照）.docx》由会员分享，可在线阅读，更多相关《公路工程标准勘察设计合同（中英文对照）.docx（26页珍藏版）》请在课桌文档上搜索。
1、公路工程标准勘察设计合同（中英文对照）总目录TAB1.EOFCONTENTS1 .般约定Generalagreement1.2 语言文字1.anguage1.3 适用法律Applicablelaw1.4 合同文件的优先顺序Priorityofcontractdocuments1.5 合同协议书ContractAgreement1.6 文件的提供和照管Provisionandcareofdocuments1.7 联络IiaiSon1.8 转让TranSfer1.9 严禁贿赂Nobribery1.10 知识产权IntelleCtUalproperty1.11 文件及信息的保密1.12 发包人要求R
2、equirementsoftheemployer2 .发包人义务Employersobligations2.2 遵守法律Compliancewiththelaw2.3 发出开始勘察设计通知Issuanceofsurvey/designcommencenotice2.4 办理证件和批件Handlingcredentialsandapprovals2.5 提供勘察设计资料Provisionofsurveyinformation2.6 其他义务Otherobligations3 .发包人管理Employersmanagement3.1 发包人代表Employersrepresentative3.2
3、监理人Supervisor3.3 发包人的指示InstructionsoftheEmployer3.4 决定或答复Decisionorreply4 .设计人义务Designersobligations4.1 设计人的一般义务Generalobligationsofdesigner4.2 履约保证金Performancebond4.3 分包不得转包Subcontractingandnotransfercontracting4.4 联合体Consortium4.5 项目负责人Projectleader4.6 勘察设计人员的管理Managementofsurvey/designpersonnel4.
4、7 撤换项目负责人和其他人员Replacementofresponsibleprojectleaderandotherpersonnel4.8 保障人员的合法权益Safeguardingthelegalrightsofpersonnel4.9 合同价款应专款专用Useofcontractpriceshouldbeearmarked5 .勘察设计要求Surveyrequirements5.1 一般要求Generalrequirements5.2 勘察设计依据Surveybasis5.3 勘察设计范围Survey/designscope5.4 勘察设计作业要求Survey/designoperat
5、ionrequirements5.5 勘察设备要求Surveyequipmentrequirements5.6 临时占地和设施要求Requirementsfortemporarylandoccupationandfacility5.7 安全作业要求Safetyrequirementsforoperation5.8 环境保护要求Environmentalprotectionrequirements5.9 事故处理要求Accidenthandlingrequirements5.10 勘察设计文件要求Survey/designDocumentRequirements6 .开始勘察设计和完成勘察设计C
6、ommencementandcompletionofsurvey/design6.1 开始勘察设计Survey/designcommencement6.2 发包人引起的周期延误Durationdelaysduetoemployer6.3 设计人引起的周期延误Durationdelayduetodesigner6.4 行政管理部门引起的周期延误Durationdelayduetoadministrativedepartments6.5 非人为因素引起的周期延误Durationdelayduetonon-humanfactors6.6 完成勘察设计Completionofsurvey/design
7、6.7 提前完成勘察设计Advancecompletionofsurvey/design7 .暂停勘察设计Suspensionofsurvey/design7.1 发包人原因暂停勘察设计Suspensionduetotheemployer7.2 设计人原因暂停勘察设计Suspensionofsurvey/designduetothedesigner7.3 暂停期间的文件照管Documentcareduringthesuspensionperiod8 .勘察设计文件Survey/designdocuments8.1 勘察设计文件接收Survey/designdocumentreception8.
8、2 发包人审查勘察设计文件Employerreviewssurvey/designdocuments8.3 审查机构审查勘察设计文件Reviewagencyreviewofsurveyanddesigndocuments9 .勘察设计责任与保险Survey/designresponsibilityandinsurance9.1 工作质量责任Responsibilityforworkquality9.2 勘察设计文件错误责任1.iabilityofsurvey/designdocumenterror9.3 勘察设计责任主体Surveyanddesignresponsiblebody9.4 勘察设
9、计责任保险Survey/designliabilityinsurance10 .招标和施工期间配合Cooperationduringbiddingandconstruction10.1 招标期间配合Cooperationduringbidding10.2 施工期间配合Cooperationduringconstruction11 .合同变更Contractamendment11.1 变更情形Changeoramendmentcircumstances11.2 合理化建议Rationalizationadvice12 .合同价格与支付Contractpriceandpayment12.1 合同价
10、格Contractprice12.2 预付款Advancepayment12.3 中期支付Interimpayment12.4 费用结算Costsettlement12.5 暂列金额Provisionalamounts12.6 质量保证金Qualityguaranteemoney13 .不可抗力Forcemajeure13.1 不可抗力的确认Confirmationofforcemajeure13.2 不可抗力的通知NoticeofForceMajeure13.3 不可抗力后果及其处理Forcemajeureconsequencesandtreatment14 .违约Default14.1 设
11、计人违约Designersdefault14.2 发包人违约Employersdefaults14.3 第三人造成的违约Defaultsduetothirdparties15 .争议的解决Settlementofdisputes部分章节示例如下：16 勘察设计要求Surveyrequirements16.1 一般要求Generalrequirements16.1.1 包人应当遵守法律和规范标准，不得以任何理由要求设计人违反法律和工程质量、安全标准进行勘察设计服务，降低工程质量。Theemployershallabidebythelaws,normsandstandards,andshallno
12、trequirethedesignertoconductsurveyservicesinviolationofIawszengineeringqualityandsafetystandardsforanyreason,reducethequalityoftheproject.16.1.2 计人应按照法律规定，以及国家、行业和地方的规颊口标准完成勘察设计工作，并应符合发包人要求。各项规范、标准和发包人要求之间如对同一内容的描述不一致时，应以描述更为严格的内容为准。Thedesignershallcompletethesurvey/designworkinaccordancewiththeIawz
13、aswellasthecodesandstandardsofStatezindustryandlocal,andshallmeettherequirementsoftheemployer.Ifanyinconsistencybetweenthespecifications,standardsandrequirementsoftheemployer,thestricterdescriptionofthecontentshallprevail.16.1.3 专用合同条款另有约定外，设计人完成勘察设计工作所应遵守的法律规定，以及国家、行业和地方的规范和标准，均应视为在基准日适用的版本。基准日之后，前
14、述版本发生重大变化，或者有新的法律,以及国家、行业和地方的规范和标准实施的，设计人应向发包人提出遵守新规定的建议。发包人应在收到建议后7天内发出是否遵守新规定的指示。发包人指示遵守新规定的，按照第11条约定执行。Unlessotherwisestipulatedintheparticularconditionshereof,thelegalrequirementsforthedesignertocompletethesurvey/designwork,aswellasStatezszindustryandlocalcodesandstandards,shallbedeemedtobeappli
15、cableonthebasedate.Ifzsubsequenttothebasedateztheaforementionedversionchangeoramendsignificantly,orifnewlawsandState,s,industryandlocalregulationsandstandardsbepromulgated,thedesignershouldadvisetheemployertocomplywiththenewregulations.Theemployershall,within7daysofreceiptoftherecommendation,giveins
16、tructionsonwhetherornotcompliancewiththenewregulations.Iftheemployerinstructcompliancewiththenewregulations,itshallexecuteinaccordancewitharticle11.16.1.4 计人在勘察设计服务中选用的材料、设备，应注明其规格、型号、性能等技术指标及适应性，满足质量、安全、节能、环保等要求,但不得指定生产厂、供应商和产品品牌。Thematerialsandequipmentselectedbythedesignerinthesurvey/designservic
17、esshallindicatetheirspecifications,models,performanceandothertechnicalindicatorsandadaptabilitytomeettherequirementsofquality,safety,energysaving,environmentalprotection,etc.,howevershallnotspecifythemanufacturersupplyandproductbrands.16.1.5 计人必须贯彻技术先进、安全可靠、适用耐久、经济合理的基本原则，加强总体设计，重视与城镇建设总体规划、土地开发利用规划
18、、农田水利、森林植被、水土保持、生态环境、特殊设施保护区、其他运输方式和其他建设工程的总体协调和配合,节约资源、保护环境、合理选用技术指标、树立全寿命周期成本的理念，充分发挥工程建设项目经济、社会和环境的综合效益。DesignersshouldimplementthebasicprinciplesofAdvancedTechnology,SafeandReliable,DurableandEconomicallyReasonable,strengthentheoveralldesign,attachimportancetotheoverallplanningofurbanconstructio
19、n,landdevelopmentandutilizationplanning,farmlandwaterconservancy,forestvegetation,soilandwaterconservation,ecologyoverallcoordinationandcoordinationofenvironment,specialfacilitiesprotectionareaszothertransportationmethodsandotherconstructionprojects,savingresources,protectingtheenvironmentrationally
20、selectingtechnicalindicators,establishingtheconceptoflifecyclecosts,andgivingfullplaytotheeconomic,socialandenvironmentaloverallbenefit.16.2 察设计依据Surveybasis除专用合同条款另有约定外，本工程的勘察设计依据如下：Exceptasotherwisestipulatedintheparticularconditionshereof,thesurvey/designbasisofthisprojectisasfollows:(1)适用的法律、行政法
21、规及部门规章；ApplicableIawszadministrativeregulationsanddepartmentalrules;(2)与工程有关的规范、标准、规程；Specifications,standards,andproceduresrelatedtotheproject;(3)工程基础资料及其他文件；Basicengineeringmaterialsandotherdocuments;(4)本勘察设计服务合同及补充合同；Thesurvey/designservicecontractandsupplementarycontract;(5)本工程施工需求；Theconstructi
22、onrequirementsoftheproject;(6)合同履行中与勘察设计服务有关的来往函件；Thecorrespondencerelatingtothesurvey/designserviceduringtheperformanceofthecontract;(7)其他勘察设计依据。Othersurveybases.16.3 察设计范围Survey/designscope16.3.1 合同的勘察设计范围包括工程范围、阶段范围和工作范围，具体勘察设计范围应当根据三者之间的关联内容进行确定。Thescopeofsurvey/designhereofincludescopesofthepro
23、ject,phaseandworkingscope.Thescopeofspecificsurvey/designshallbedeterminedbasedoncontentoftherelevancecontentsofthethreescopes.16.3.2 程范围指勘察设计工程的建设内容，具体范围在专用合同条款中约定。Scopeoftheprojectreferstoconstructioncontentofthesurvey/designedproject,andspecificscopeisstipulatedinthestipulationofparticularconditi
24、onshereof.16.3.3 段范围指工程建设程序中的可行性研究勘察设计、初步勘察设计、详细勘察设计、施工勘察设计、方案设计、初步设计、技术设计(如有)、施工图设计等阶段中的一个或多个阶段，具体范围在专用合同条款中约定。Stagescoperefertooneormorestagesinthefeasibilitystudysurvey,preliminarysurvey,detailedsurvey,constructionsurvey,schemedesign,preliminarydesign,technicaldesign(ifany),constructiondrawingdes
25、ign,etc.intheconstructionprocessoftheproject.Thespecificscopeisstipulatedintheparticularconditionsofcontract.16.3.4 作范围指工程测量、岩土工程勘察设计、岩土工程设计(如有)，编制设计文件,编制设计概算、预算，提供技术交底、招标与施工配合，编制竣工图，参加交工验收、参加竣工验收和发包人委托的其他服务中的一项或多项工作，具体范围在专用合同条款中约定。Thescopeofworkrefertoengineeringsurveys,geotechnicalengineeringsurve
26、ys,geotechnicalengineeringdesigns(ifany),preparationofdesigndocuments,preparationofdesignestimates,budgets,provisionoftechnicaldetails,biddingandconstructioncoordination,preparationofas-builtdrawings,participationinacceptanceinspectioninadditiontoparticipateinoneormoretasksofcompletionacceptanceando
27、therservicesentrustedbytheemployer,thespecificscopeofwhichisstipulatedintheparticularconditionsofcontract.16.4 察设计作业要求Survey/designoperationrequirements16.4.1 绘Survey/designingandMapping(1赊专用合同条款另有约定外,发包人应在开始勘察设计前7日内，向设计人提供测量基准点、水准点和书面资料等；设计人应根据国家测绘基准、测绘系统和工程测量技术规范，按发包人要求的基准点以及合同工程精度要求，进行测绘。Exceptas
28、otherwisestipulatedintheparticularconditionshereof,theemployershall,within7daysbeforecommencementofthesurvey/design,providethedesignerwiththemeasurementreferencepoints,benchmarkpointsandwrittenmaterials;thedesignershallperformsurvey/designingandmappinginaccordancetoStatezssurvey/designingandmappings
29、tandards,survey/designingandmappingsystemandengineeringmeasurementtechnicalspecificationsornorms；inadditiontothebasisofthebenchmarksandtheaccuracyrequirementsofthecontractengineeringwhichrequiredbytheemployer.(2)设计人测绘之前，应认真核对测绘数据，保证引用数据和原始数据准确无误。测绘工作应由测量人员如实记录,不得补记、涂改或损坏。Thedesignershall,priortosurv
30、ey/designingandmapping,carefullycheckthedataofsurvey/designingandmappingtoensuretheaccuracyofthequoteddataandoriginaldata.Thesurvey/designingandmappingworksshallberecordedbythesurvey/designingpersonneltruthfullyandshallnotbeafter-recorded,alteredordamaged.(3)工程勘探之前，设计人应严格按照勘察设计方案的孔位坐标，进行测量放线并在实地位置定位
31、，埋设带有编号且不易移动的标志桩进行定位控制。Thedesignershall,priortoexplorationoftheproject,makemeasurethepay-offlineandlocateitinthefieldpositionstrictlyfollowtheholepositioncoordinatesofthesurvey/design/designplan,andburythemarkedpilewithnumberedanddifficulttomoveforpositioningcontrol.16.4.2 勘探Exploration(1)设计人应根据公路基本
32、建设程序各阶段要求的深度开展工作，结合现场地形地质条件、工程结构设置以及不同勘察设计手段的特性等，统筹考虑、综合确定勘察设计方法及勘察设计工作量，为完成合同约定的勘察设计任务创造条件。设计人对于勘察设计方法的正确性、适用性和可靠性完全负责。Thedesignershallcarryouttheworkinaccordancewiththedepthrequiredateachstageofthehighwayinfrastructureconstructionprocess,andConsiderthesitegeologicalconditions,engineeringstructures
33、ettings,andcharacteristicsofdifferentsurveymethods,andconsiderandcomprehensivelydeterminethesurvey/designmethodandsurveyworkload,createconditionsforcompletionofcontractualsurveyanddesigntasks.Thedesignerisfullyresponsibleforthecorrectness,applicabilityandreliabilityofthesurvey/designmethod.(2)设计人布置勘
34、探工作时，应充分考虑勘探方法对于自然环境、周边设施、建构筑物、地下管线、架空线和其他物体的影响，采用切实有效的措施进行防范控制，不得造成损坏或中断运行，否则由此导致的费用增加和(或)周期延误由设计人自行承担。Thedesignersshall,atthetimeofarrangementofexplorationworkzfullyconsidertheimpactofexplorationmethodsonthenaturalenvironment,surroundingfacilities,buildings,undergroundpipelines,overheadlinesandoth
35、erobjects,andtakeeffectivemeasurestopreventandcontrol,andshallnotcausedamageorinterruptionoperation,otherwisetheresultingincreaseincostsand/orcycledelaysshallbebornebythedesigner.(3)设计人应在标定的孔位处进行勘探，不得随意改动位置。勘探方法、勘探机具、勘探记录、取样编录与描述，孔位标记、孔位封闭等事项，应严格执行规范标准，按实填写勘探报表和勘探日志。Thedesignershallconductexploratio
36、natthemarkedholepositionandshallnotarbitrarilychangetheposition.Themethods,equipment,recordsofexploration,samplinganddescription,holemarking,holesealing,etc.shouldstrictlybeimplementedbythenormsandstandards,fillintheexplorationreportandexplorationlogaccordingtotheactualsituation.(4)勘探工作完成后，设计人应按照规范要
37、求及时封孔，并将封孔记录整理存档，勘探场地应地面平整、清洁卫生，并通知发包人、行政主管部门及使用维护单位进行现场验收。验收通过之后如果发生沉陷，设计人应及时进行二次封孔和现场验收。Thedesignershall,subsequenttocompletionoftheexplorationworkzsealtheholesintimesubjecttotherequirementsoftheregulations,andarchivethesealingrecords.Theexplorationsiteshallbeleveled,cleanandhygienic,andnotifythee
38、mployer,theadministrativedepartmentandtheuse/maintenanceunittoconducton-siteinspectionandacceptance.Ifthesubsidenceoccursaftertheacceptance,thedesignershallpromptlyperformthesecondsealingandon-siteacceptance.16.4.3 取样5.4.3Sampling(1)设计人应针对不同的岩土地质，按照勘探取样规范规程中的相关规定，根据地层特征、取样深度、设备条件和试验项目的不同，合理选用取样方法和取样
39、工具进行取样，包括并不限于土样、水样、岩芯等。Thedesignershall,fordifferentrockandsoilgeology,selectsamplingmethodsandsamplingtoolsforsamplinginaccordancewiththerelevantregulationsintheexplorationsamplingspecificationandsubjecttostratumcharacteristics,samplingdepth,equipmentconditionsandtestitems,includingsoilsamples,wate
40、rsamples,drillcores,etc.(2)取样后的样品应根据其类别、性质和特点等进行封装、贮存和运输。样品搬运之前，宜用数码相机进行现场拍照；运输途中应采用柔软材料充填、尽量避免震动和阳光曝晒；装卸之时尽量轻拿轻放，以免样品损坏。Samplesaftersamplingshallbeseal-packaged,storedandtransportedsubjecttotheirtype,natureandcharacteristics.Beforecarryingthesample,itisadvisabletotakeaphotowiththedigitalcamera.Soft
41、materialsshouldbeusedduringtransportationtoavoidvibrationandsunexposureasfaraspracticable;Takethesamplesaslightlyaspossibleduringloadingandunloadingtoavoidsampledamage.(3)取样后的样品应填写和粘贴标签，标签内容包括并不限于工程名称、孔号、样品编号、取样深度、样品名称、取样日期、取样人姓名、施工机组等。Thesampleaftersamplingshallbefilledinandaffixedwithlabels.Thecon
42、tentsthereofincludenotlimitedtotheprojectname,holenumber,samplenumber,samplingdepth,samplenamezsamplingdatezsamplersname,constructiongroup,etc.5.4.4试验5.4.4Test(1)设计人应根据岩土条件、设计要求、勘察设计经验和测试方法特点，选用合适的原位测试方法和勘察设计设备进行原位测试。原位测试成果应与室内试验数据进行对比分析，检验其可靠性。Thedesignershallselecttheappropriatein-situtestmethodan
43、dsurvey/designequipmentforin-situtestinginaccordancewithgeotechnicalconditions,designrequirements,survey/designexperienceandtestmethodcharacteristics.In-situtestresultsshouldbecomparedwithlaboratorytestdatatoverifytheirreliability.(2)设计人的试验室应通过行业管理部门认可的CMA计量认证，具有相应的资格证书、试验人员和试验条件，否则应委托第三方试验室进行室内试验。T
44、helaboratoryofthedesignershallpasstheCMAmeasurementcertificationapprovedbytheindustrymanagementauthority,andholdthecorrespondingqualificationcertificates,testpersonnelandtestconditions.Otherwise,thethird-partylaboratoryshallbeentrustedtoconductindoortest.(3)设计人应在试验之前按照要求清点样品数目，认定取样质量及数量是否满足试验需要；勘察设计
45、设备应检定合格，性能参数满足试验要求，严格按照规范标准的相应规定进行试验操作；试验之后应在有效期内保留备样，以备复核试验成果之用，并按规范标准规定处理余土和废液，符合环境保护、健康卫生等要求。Thedesignershallcheckthenumberofsamplesasrequiredbeforethetesttodeterminewhetherthequalityandquantityofthesamplemeetthetestrequirements;Thesurvey/design/designequipmentshallbequalified,theperformanceparam
46、etersshallmeetthetestrequirements,andthetestoperationshallbecarriedoutinstrictpursuanttothecorrespondingprovisionsofthestandard;Thesampleshould,subsequenttothetest,bekeptwithinthevalidityperiodinpreparationforreviewingthetestresults,andtheresidualsoilandwasteliquidshouldbedisposedsubjecttothestandar
47、dandmeettherequirementsofenvironmentalprotection,healthandsanitation.(4)试验报告的格式应符合CMA计量认证体系要求，加盖CMA章并由试验负责人签字确认；试验负责人应通过计量认证考核，并由项目负责人授权许可。TheformatofthetestreportshallcomplywiththerequirementsoftheCMAmeasurementandcertificationsystem,andshallbestampedwiththeCMAandsignature/confirmationofthetestlead
48、er;Thepersoninchargeofthetestshallpassthemeasurementcertificationassessmentandbeauthorizedbytheprojectleader.5.4.5其他要求5Otherrequirements(1)设计人应在勘察设计过程中重视地质环境对安全的影响，提交的勘察设计报告应真实、准确、可靠，满足工程安全生产的需要，并对勘察设计结论负责。Thedesignershallpayattentiontotheimpactofthegeologicalenvironmentonsafetyduringthesurvey/design.Thesurvey/designreportsubmittedshallbetrue,accurate,reliableandmeettheneedsofprojectsafetyproduction,andberesponsibleforthesurvey/designconclusions.(
